当前位置：聚优网>实用文>合同范本>英文合同

英文合同

时间：2024-09-14 19:44:02 合同范本我要投稿

英文合同范文汇编八篇

　　在当今不断发展的世界，合同的法律效力与日俱增，签订合同能促使双方规范地承诺和履行合作。那么大家知道合同的格式吗？以下是小编为大家收集的英文合同8篇，仅供参考，欢迎大家阅读。

英文合同范文汇编八篇

英文合同篇1

　　Contract

　　Vendee：

　　[ Myself]【Legal representative】 Name：

　　【ID card】【 Passport】【Business license registration number】【】Address：Zip code： Telephone：

　　【Entrusted agent】【】Name： Nationality: Address：Zip code： Telephone：

　　According to the《People's Republic of China Law of contract》, 《People's

　　Republic of China City Real estate Control law》 and other relevant laws

　　and regulations，The vendee and seller should be base on the equality,

　　voluntarily, Consults unanimously foundation to reach the following

　　agreements about buy and sell the commodity apartments 。

　　Article 1Project construction basis 【contract number for granting of land-use right 】【document number for

　　allowing and authorizing of land-use right】【document number for transferring

　　and authorizing of land-use right】This land area is age is limited from to By approving of seller, construct the commercial residential houses in the

　　above land parcel, 【present name】,【 temporary name 】

　　, the builder’s permit

　　licence number is

　　Article 2Residential basis.

　　The residential is 【completed apartment】【the selling apartment in

　　advance】,the total

　　total area is ,the buyer has already Purchased

　　of presale fund specified account is ,

　　Article 3 fundamental state of vendee’s commercial residential building.

　　vendee’s commercial residential building(hereinafter referred to as the

　　commercial building, the house plan is specified in appendix 1 to the contract,

　　room number is bases on the appendix 1 details )which stipulated in the first

　　article of the contract is:

　　【tents】（）specific house number is

　　unitlayer】Commercial building’s use which is approved by planning department is

　　_㎡，there are ㎡，__㎡.

　　The balcony of this apartment is [sealed] or [not sealed].

　　as [stipulated on contract]

　　or [property registration]. The Usable Area ㎡, with Public area to be

　　( refer to the attachment2 for Public area to be shared

　　construction explanation )

　　Article 4 Valuation Mode & price /㎡According to the Usable area, the unit price of this apartment /㎡According to the Usable area, the unit price of this apartment /㎡should subject to the related regulation of [opinions on the

　　strengthening of commercial residential building presale capital supervision,

　　and issue the [commercial residential building presale receipts notification]

　　from Yantai residential administration bureau. The buyer transfer the capital to

　　the designated bank directly, the seller cannot get the presale capital directly.

　　Article 5 Area confirmation& difference treatment

　　According to the valuation mode which interested parties choosed, this article

　　stipulates the area confirmation&difference treatment according to [building

　　area][usable area]( hereinafter called area for short).

　　This article does not apply to the interested parties which charge the apartment

　　by set.

　　The property registration area will be subject to the surveying and drawing

　　report issued by qualified mapping unit designated by residential

　　administration dept.

　　For any differences in contracted area& registration area, the registration area

　　will be taken as the standard.

　　After the apartment is transferred to the buyer, for any differences in contracted

　　area& registration area, which was not stipulated in the contract, both parties

　　will agree to manage according to the following principle: charge as per actual

　　area, Return the overcharge and demand payment of the shortage on the

　　prepaid capital.

　　1.if the absolute value difference is within 3%( include 3%), the charge will be

　　according to actual amount.

　　1.if the absolute value difference is exceeds 3%( include 3%), the buyer has

　　rights to cancel the order.

　　For the buyer who cancel the order, the seller must return the money to buyer

　　within 30days after buyer make the order cancel application, and pay the

　　For the buyer who will not cancel the order, if the registration areas is within

　　3%(including 3%) bigger than contracted area, the exceeded amount shoud be

　　supplemented by the buyer; for the case which is more than 3%, the exceeded

　　amount should be born by the seller, the property rights belongs to the buyer. If

　　the registration areas is smaller than contracted area, the area ratio is within

　　3%((including 3%), the exceeded amount must be returned to the buyer; the

　　amount which are more than 3%

　　must be doubled and return to the buyer. This

　　article is not applicable.

　　Area tolerance ratio=( registration areas- contracted area)/ contracted

　　areaX100%. This article is not applicable.

　　The difference caused by the design modification, which both parties does not

　　terminate the contract, buyer and seller should sign complementary agreement

　　of contract.

　　Article6 payment& deadline

　　nd1. Full Payment

　　2. installment payment

　　3.others

　　Article7 the Breach of contract responsibility for overdue payment

　　If the buyer cannot effect the payment in the stipulated time, he or she will be

　　ndnd due payment date to the

　　actual payment date, the buyer should pay to the fine

　　according to the overdue date, the contract will continue to be performed.

　　2) If the overdue date is exceeds__days, the buyer has the rights to terminate

　　the contract. If so, the buyer should pay to the fine

　　according to the overdue date, the contract will continue to be performed, from

　　the 2nd due payment date to the actual payment date, the buyer should pay to

　　to the overdue date.

　　The overdue payment in this article refers to the balance between 6th article

　　due payment and acutal effected payment; for installment payment, it should

　　be decided by the balance between due istallment and actual payment.

　　Article8 handover deadline

　　According to the state’s and local government regulations, the seller should handover the commercial residential building, which possess the below 1

　　1. this commercial residential building is inspected to be qualified.

　　2. this commercial residential building is comprehensively inspected to be qualified.

　　3. this commercial residential building is installment inspected to be qualified.

　　4. this commercial residential building obtained the approval documents of commercial residential handover for usage.

　　But in case of the following exceptional reasons, except for both parties agree the termination or alternation of contract, the seller can prolong the deadline as per actual fact.

　　1. encountered with majeure, and seller informed the buyer within 30 days after the majeure occurs;

　　2. the seller caused the project cannot be finished on time because of non-controllable reasons.

　　3. If the delay is because of the above cases, this article is also applicable.

　　Article9 responsibility of delay in handover apartment

　　Except for the special cases stipulated in article8, if the seller cannot handover the apartment to buyer in the stipulated schedule in this contract, the buyer should be treated in the following 1st&2nd mode:

　　1. According to the overdue time, the seller should be treated separately( not

　　be accumulated)

　　1) For overdue date less days, from the 2nd day of deadline

　　stipulated in article8 to the payment day, the buyer should pay _____% default fine of the already effected payment, this contract will be performed continuously.

　　2) For overdue date more days, the buyer can terminate the

　　contract. In this case, the seller should return all the payment within 30days after the date of termination, and pay __2___% default fine of the already effected payment. If the buyer request continuously perform the contract, this contract will be performed continuously. from the 2nd day of deadline stipulated in article8 to the payment day, the rates in 1) )of the already effected payment

英文合同篇2

　　农信借字( )第号

　　贷款人：

　　借款人：经贷款人、借款人协商一致，根据国家有关法律、法规、规章的

　　规定、签订本合同，共同遵守。

　　第一条贷款人同意向借款人发放以下内容贷款：

　　(一)贷款种类：

　　(二)借款用途：

　　(三)借款金额 (大写)

　　(四)借款期限：自年月月日止。具体用款、还款计划如下(略)

　　(五)贷款利率：

　　(六)还款方式：

　　第二条借款人承诺：

　　(一)按期归还贷款本息;

　　(二)按合同约定使用贷款，不攘自改变借款用途;

　　(三)向贷款人按月提供真实的资产负债珍、损益珍及所有开户行、账号等资料;

　　(四)接受贷款对其信贷资金使用情况和有关生产经营、财务活动的检查监督;

　　(五)用本企业资产对他人债务进行担保，应事先通知贷款，并不得影响贷款人到期收回贷款;

　　(六)法定人代表人变更、法人住所或经营场所及注册资金发生变动时，应事先通知贷款人;

　　(七)因实行承包、租凭、联营、股份制造、分立、被兼并(合并)、产权有偿转让、对外投资等体制变更时必须提前通知贷款人并落实还款措施。

　　第三条贷款人承诺

　　(一)按期、按额向借款方提供贷款;

　　(二)不向借款人收取合同以外的费用;

　　(三)对借款人的债务、财务、生产、经营情况保密。

　　第四条借款方因特殊情况不能按期偿还贷款，应在贷款到期前天内向贷款方提出书面申请。经贷款人同意，签订展期协议后，方可延长还款期限，但贷款利率要按累计期限档次确定。

　　第五条违约责任：

　　1、不按期归还贷款本金又获准展期，从逾期之日起利率万分之计收利息;

　　2、不按期偿付贷款利息，贷款人对借款人款支付的利息计收复利;

　　3、不按合同规定使用贷款，按挤占挪用处理，此期间对挤占挪用部分按日利率万分之计收利息。

　　4、违反本合同第二条(二)至(七)项，贷款人有权停止本合同尚款发放的贷款提前收回尚款到期的'贷款。

　　(二)贷款人违约：

　　1、贷款人不能按期、按额向借款人提供资金时，按违约数额和延期天数处以日利率万分之的违约金;

　　2、违反第三条(二)项时借款人有权拒绝，违反第(三)项时，可向人民银行投诉;

　　第六第贷款到期收回贷款或依照本合同条五条提前收回贷款均可直接从借款人账户中扣收。

　　第七条本合同发生纠纷

　　1、由贷款人住所地人民法院解决。

　　2、提交沧州仲裁委员会促裁解决。

　　第八条其他约定事项

　　第九条本合同未尽事宜，遵照国家有关法律、法规和规章办理。

　　第十条本合同一式二份，借款、贷款人各待一份。本合同自各方签章之起生效。

　　签约时间年月日

　　签约地点

英文合同篇3

　　DATE :C/NO :

　　Inv. No:

　　PART A:

　　PART B:

　　BOTH OF THE 2 COMPANIES ( PART A AND PART B) AGREED

　　TO PAY THE COMMISSION FOR THE BUSINESS BETWEEN THEM AS FOLLOWS:

　　1. BUSINESS ITEMS:

　　PRODUCTS:FABRIC

　　QUANTITY:76000M(CONTRACT)

　　PRICE:FOB USD7.45/M ECT.

　　AMOUNT: USD593,500.00(CONTRACT)

　　AMOUNT: USD531,622.55(ACTUALLY)

　　2. COMMISSION ITEMS:

　　COMMISSION: FOR THE TOTAL AMOUNT .

　　COMMISSION AMOUNT: USD21,124.70

　　3. PAYMENT ITEMS:

　　PART A SHOULD PAY THE COMMISSION BY T/T .

　　Confirmed By:

　　PART A: PART B:

　　DATE :C/NO :

　　Inv. No:

　　PART A:

　　PART B:

　　BOTH OF THE 2 COMPANIES ( PART A AND PART B) AGREED TO PAY THE COMMISSION FOR THE BUSINESS BETWEEN THEM AS FOLLOWS:

　　3. BUSINESS ITEMS:

　　PRODUCTS:MEN’S SUITS

　　QUANTITY:2877UNDS

　　PRICE:FOB EUR40.60/UNIT

　　AMOUNT: EURO116,806.20

　　4. COMMISSION ITEMS:

　　COMMISSION: FOR THE TOTAL AMOUNT .

　　COMMISSION AMOUNT: USD5700.00

　　3. PAYMENT ITEMS:

　　PART A SHOULD PAY THE COMMISSION BY T/T .

　　Confirmed By:

　　PART A: PART B:

英文合同篇4

　　(Translation)

　　Mortgage Contract

　　No. J.K.D.20xx—032

　　hereinafter referred to as the main contract) signed by (borrower) and Party A Party B is willing to use the property owned or disposable according to laws as mortgage; Through verification, Party A agrees to accept the property mortgage of Party B;

　　According to relevant laws and regulations, based on mutual negotiations, Party

　　A and Party B make agreement in the following articles:

　　Article 1 Collateral of Party B

　　Party B uses the property in the List of Collateral (appendix) for mortgage. Party

　　B guarantees its ownership or right of disposal according to laws.

　　Article 2 Method of Mortgage Guarantee

　　1. When the debt stipulated in the main contract is due, the guarantee responsibility of the loan provided by Party A to Party B yet not repaid by Party B is ascertained according to the scope of mortgage guarantee in Article 3 of this contract; before the debt stipulated in the main contract is due, if Party A conducts recourse on the borrower in advance according to the main contract, Party B shall also take the guarantee responsibility with the collateral.

　　2. If Party A and Party B (or borrower) make written agreement of extending duration on the debt duration, interest rate, amount and etc. stipulated in the main contract, or Party A makes an adjustment in the interest rate according to the main contract during the debt duration stipulated in the main contract, it is not necessary to

　　get consent from Party B or to inform Party B and Party B agrees to all, then the mortgage guarantee responsibility undertaken by Party B shall not be affected.

　　Article 3 Scope of Mortgage Guarantee

　　The scope of mortgage guarantee includes the entire principal stipulated in the main contract, interest, overdue interest, penalty interest, compound interest, default fine, compensation for loss, all charges to enforce the mortgage right and realize the creditor’s rights (including but not limited to legal costs, arbitration fees, costs of preservation, announcement fees, assessment fees, appraisal charges, auction costs, travel expenses, communication expenses, counsel fees and etc.) and all other payable expenses of the debtor in the main contract.

　　Article 4 Custody of Ownership Certificate and Registration

　　of the Collateral

　　Party B shall deliver ownership certificate of the collateral to Party A on the date of contract signing, and both parties agree that within days after the contract is signed, Party B shall unconditionally assist Party B with relevant mortgage registration procedures. Ownership certificate of the collateral shall be in the custody of Party A during mortgage period.

　　Article 5 When there are other mortgage guarantee, pledge guarantee or guarantees in the creditor’s rights of Party A, if Party A gives up or removes other mortgage guarantee and pledge guarantee or dismisses guarantee responsibility of guarantees, Party B shall still take mortgage guarantee responsibility regarding Party

　　A according to articles stipulated in this mortgage contract.

　　If Party A suspends granting the loan that has not been granted or collects granted loan in advance based on the articles in the main contract, the guarantee responsibility undertaken by Party B according to this contract shall not be affected.

　　Article 6 Cost Bearing

　　Relevant costs stipulated in this contract such as assessment fees, insurance premium, appraisal charges, registration fees, custody charges and etc.

　　Article 7 Custody of the Collateral

　　1. During the mortgage period, the collateral shall be in custody of Party B or the entrusted agent of Party B; Party B and the entrusted agent of Party B shall maintain proper custody of the collateral and have the obligation of repair, maintenance and keeping it intact and shall accept the inspection of Party A at any time.

　　The mortgage period refers to the period from the day this contract comes into effect to the expiration day of statute of limitations of creditor’s rights stipulated in the Loan Contract.

　　2. During the mortgage period, Party B shall not take any actions that will reduce the value of the collateral; if such actions occur, Party A has the right to demand Party B to stop and recover the value of the collateral, or to provide new collateral accepted by Party A within 2 days after Party A informs Party B. Costs resulted from the recovery of the collateral of providing new collateral shall be undertaken by Party B.

　　3. Party B shall purchase property insurance for the collateral during the mortgage period, and the first beneficiary of the property insurance shall be Party A. Insurance documents shall be in custody of Party A. During the mortgage period, if losses within the insurance scope of the collateral occur or the value of the collateral is reduced because of the actions of the third party, insurance compensation or compensation for losses shall be used to liquidate the debt stipulated in the main contract in advance or shall be deposited by Party B in the account appointed by Party A, and Party B shall not use during the mortgage period.

　　Article 8 During the mortgage period, if the collateral causes environmental pollution or other damages, Party A alone shall take the responsibility.

　　Article 9 During the mortgage period, without written consent from Party A, Party B shall not give away, remove, rent, transfer, remortgage or dispose in other ways the collateral stipulated in this contract.

　　Article 10 During the mortgage period, with written consent from Party A, payment received from the transfer of the collateral by Party B shall be used to liquidate the mortgaged creditor’s rights of Party A in advance.

　　Article 11 In the expiration of the time limit of the main contract, if the borrower cannot liquidate the debt, Party B has the right to discount the collateral or take priority in compensation with the payment from the auction or selling off of the collateral.

　　Article 12 Party A has the right to realize the mortgage right through disposal of the collateral in advance, suspend the grant of loan stipulated in the main contract or collect the principal and interest of the granted loan stipulated in the main contract in advance when one of the following circumstances occur:

　　1. There are defaults of the articles or agreement stipulated in the main contract made by the borrower;

　　2. There are violations of in the agreed responsibility stipulated in Article 4, Article 7, Article 8, Article 9 and Article 10 of this contract or other actions of defau< or Party B fails to fulfill resposibilities stipulated in this contract.

　　3. When Party B is a legal person or other organizations, situations that will affect its ability to liquidate debts or lack of good faith in debt liquidation occur such as suspension of business, suspension or annulment of business license, application or

　　being applied for bankruptcy, dissolution and etc.

　　4. When Party B is a natural person, death without heirs or devisees occurs;

　　5. When Party B is a natural person, heirs or devisees of Party B give up the inheritance or bequest and refuse to fulfill the obligation of repaying loan principal and interest;

　　6. Other events that will endanger the realization of creditor’s rights of Party A stipulated in the main contract.

　　Article 13 Responsibility for Breach of Contract

　　1. If Party B violates Article 7 of the contract through reduction in the value of the collateral resulting from the carelessness in the repair and management of the collateral, or actions of Party B directly endanger the collateral and result in the reduction in the value of the collateral, Party A has the right to demand Part B to immediately stop the violating actions towards the mortgage right of Party A, to demand Party B to provide other collateral accepted by Party A, and to dispose the collateral in advance.

　　2. If Party B violates Article 9 of the contract and arbitrarily disposes the collateral, the action is not valid; Party A has the right to demand Part B to immediately stop the violating actions towards the mortgage right of Party A, to demand Party B to provide other collateral accepted by Party A;

　　3. If Party B conceals the fact that the collateral is involved in co-ownership, disputes, seal-up, impoundment, rent, existing mortgage, legal priority right with lower mortgage right (including but not limited to priority right of construction project payment) or no ownership or disposal right of Party B and etc., Party A has the right to demand Party B to provide other collateral/ pledge property accepted by Party A;

　　4. When any of the above circumstances violating the contract occurs, if Party B fails to provide other collateral according to the requirements of Party A, Party B shall pay Party B a default fine amounting to of the loan principal stipulated in the main contract. If economic losses are caused to Party A, Party B shall compensate Party A for all the economic losses.

　　Article 14 Payment from Exercise of the Mortgage Right by Party A Shall be Assigned in Priority of the Following Order:

　　1. Payment of charges related to the exercise of the mortgage right;

　　2. Liquidation of interest payable by the borrower to Party A;

　　3. Liquidation of loan principal, default fine (including penalty interest), compensation and etc. payable by the borrower to Party A;;

　　4. Payment of other cost.

　　Article 15 Delivery

　　Except for other agreement, both parties designate the communication method and contact address stipulated in the contract as the basis, and any written notification delivered to the address shall be considered effective arrival. Party B shall promise that if there is any change in the communication method and contact address, Party A fails to notify the other party about the change in the communication method or contact address according to the agreement resulting in this party not receiving the notification from the other party, this party shall undertake corresponding consequences by itself.

　　The signing of personnel authorized by Party B or arranged by Party A for come-and-go files, legal papers or relevant notifications shall be regarded as the arrival to Party B, except that Party B explicitly notifies Party A in the written form that the personnel is not entitled to sign the come-and-go files, legal papers or relevant notifications.

　　Article 16 Terms of Compulsory Execution

　　1. Party A and Party B both confirm that according to relevant laws and regulations, they have specific understanding of the definition, content, procedure and effect of notarization that gives compulsory execution effect, and through conscious consideration, all parties agree to apply to the notarization authority for notarization and give this contract effect of compulsory execution.

　　2. Party B promises to accept compulsory execution according to laws when failing to fulfill or completely fulfill obligation of repayment stipulated in the contract; Party B gives up the right of pleadings.

　　3. When Party B fails to fulfill relevant obligations stipulated in the contract, Party A has the right to conduct collection and interpellation to Party B through mail delivery, telephone notification, announcement delivery and etc. Party B shall fulfill relevant obligations stipulated in the contract within three days after the collection and interpellation of Party A. If Party B still fails to fulfill relevant obligations stipulated in the contract, Party A has the right to apply to notarization authority for execution certificate.

　　4. Agreed items in advance about the verification contents and methods of the notarization authority before the Execution Certificate is issued: if Party B fails to fulfill or completely fulfill guarantee responsibility, Party A provides the notarization authority with evidence of Party B’s failure of fulfillment. Based on the application of Party A, before the Execution Certificate is issued, the notarization authority verifies the fact of Party B’s failure of fulfillment or proper fulfillment of guarantee responsibility through letters or telephones (faxes) according to the contact address or contact telephone stipulated in the contract before. Party B shall substantially respond to the verified contents made by the notarization authority within five days according to the requirements of the notarization authority, otherwise no disagreement from

英文合同篇5

　　合约编号：＿＿＿＿＿＿＿＿

　　contract no.＿＿＿＿＿＿＿

　　售货合约 sales contract

　　买方：＿＿＿＿＿日期：＿＿＿＿年＿＿月＿＿日

　　buyers:＿＿＿＿＿ cate:＿＿＿＿＿

　　卖方：＿＿＿＿中国＿＿＿进出口公司＿＿＿省分公司

　　sellers: china national metals & minerals import & export corporation,____branch

　　双方同意按下列条款由买方购进卖方售出下列商品：

　　the buyers agree to buy and the sellers agree to sell the following goods on terms and conditions set forth below:

　　──────────────┬───────┬──────┬──────

　　（１）货物名称及规格，包装及│ （２）数量 │ （３）单价 │ （４）总价

　　装运唛头 │ │ │

　　name or commodity and speci-│ quantity │ unit price │ total

　　fications packing and shipp-│ │ │amount

　　ing marks │ │ │

　　──────────────┼───────┼──────┼──────

　　（装运数量允许有％的增减）│ │ │

　　（shipment quantity % more │ │ │

　　or less allowed │ │ │

　　──────────────┴───────┴──────┴──────

　　（５）装运期限

　　time of shipment:

　　（６）装运口岸

　　ports of loading

　　（７）目的口岸

　　port of destination:

　　（８）保险：投保＿＿＿险，由＿＿＿按发票金额＿＿＿％，投保

　　insurance: covering risks for____% of invoice value to be effected by the

　　（９）付款条件：＿＿＿……

　　terms of payment:＿＿＿凭保兑的，不可撤消的，可转让的，可分割的即期

　　付款信用证，信用证以中国五金矿产进出口公司＿＿分公司为受益人并允许分批装运和转船。

　　by confirmed irrevocable, transferable and divisible letter of credit in favour of china national metals & minerals import & export corporation___branch payable at sight allowing partial shipments and transhipment.

　　该信用证必须在＿＿＿前开到卖方，信用证的`有效期应为装船期后１５天，在上述装运口岸到期，否则卖方有权取消本售货合约并保留因此而发生的一切损失的索赔权。

　　注意：开立信用证时，请在证内注明本售货确认书号码

　　china national

　　texties import and

　　export corporation

　　important: when establishing l/c, please

　　indicate the mumber of this sales

　　shantung branch

　　confirmation in the l/c.

　　买方（the buyers）：＿＿＿＿＿

　　卖方（the sellers）：＿＿＿＿＿

　　请在本合同签字后寄回一份存档

　　please sign and return one copy for out file.

英文合同篇6

　　ABC 服饰有限公司

　　ABC Garments & Accessories Co., Ltd

　　售货合约SALES CONTRACT

　　合同编号CONTRACT NO.ABC091102

　　日期DATE NOV. 02, 20xx

　　买方BUYER Arrabon Trading ,Unit 9, Central Office Park,

　　257 Jean Ave, Centurion

　　Tel: +357 27 664 0587 Fax: +357 27 664 0586

　　卖方SELLER ABC GARMENTS & ACCESSORIES CO., LTD

　　HONGXIN ROAD, HANGZHOU, ZHEJIANG,CHINATEL: FAX:

　　双方同意按下列条款由买方购进卖方售出下列商品:

　　The Buyers agree to buy and the Sellers agree to sell the following goods on terms and conditions as set forth below :

　　(1) 货物名称及规格,包装及装运墨头| (2) 数量 |(3) 单价| (4) 总价

　　Name of Commodity, Specifications, QuantityUnit Price Total Amount

　　boy’s denim long pant 1000PCSUSD9.50 USD9500.00 boy’s twill long pant1000PCS USD10.00 USD10000.00TOTAL: USD19500.00 SPECIFICATION AS BELOW:

　　Fabric: 100% cotton, 8 oz denim/40s40s 133/72 twill

　　Size: 9 – 36 month,Long pant with front mock(fake) fly,

　　waistband stud opening,back elastic with belt loops.

　　PACKING:

　　One polybag per pc, 10 pcs a carton-box, solid color/

　　per carton-box, 5 moisture-proofing agentper carton-box,

　　an inner-cover-cardboard per carton-box

　　MARK:

　　MAIN MARK :SIDE MARK:

　　ARRABONARRBON

　　DESRRIPTION:N.W.:

　　COLOR: G.W.:

　　QTTY :20xxPCSNO.: 1 TO UP/TOTAL CTN NOS.

　　(装运数量允许有5%的增减 Shipping QuantityFive Percent More or Less Allowed)

　　(5) 装运期限Time of Shipment50DAYS AFTER THE SELLER RECEIVE THE L/C.

　　(6) 装运口岸Port of loading SHANGHAI

　　(7) 目的口岸Port of Destination LIMASSOL, CYPRUS

　　(8) 保险投保InsuranceALL RISK AND WAR RISK COVERED BY BUYER

　　(9) 付款条件Terms of Payment IRREVOCABLE L/C AT SIGHT

　　该信用证必须在 45天前开到卖方, 信用证的有效期应为装船期后15天, 在上述装运口岸到期,

　　否则卖方有权取消本售货合约并保留因此而发生的一切损失的索赔权 .

　　The covering Letter of Credit must reach the Sellers 45 Days Prior to the Shipment Date and is to

　　remain valid in above indicated Loading Ports 15 days after the date of shipment, failing which the Sellers reserve the right to cancel this Sales Contract and to claim from the Buyers compensation for losses resulting therefrom.

　　其他条款 OTHER TERMS :

　　（1）异议 : 品质异议须于货到目的口岸之日起30天内提出,数量异议须于货到目的`口岸之日起15天内提出。但均须提供经卖方同意的公证行的检验证明. 如责任属于卖方者卖方

　　于收到异议20天内答复买方并提出处理意见.

　　QUALITY/QUANTITY DISCREPANCY: In case of quality discrepancy, claim should be filed

　　by the Buyers within 30 days after the arrival of the goods at port of destination, while for quantity discrepancy claim should be filed by the Buyers within 15 days after the arrival of the goods at

　　port of destination. In all cases, claims must be accompanied by Survey Reports of Recognized

　　Public Surveyors agreed to by the Sellers. Should the responsibility of the subject under claim

　　be found to rest on part of the Sellers, the Sellers shall, within 20 days after receipt of the claim,

　　send his reply to the Buyers together with suggestion for settlement.

　　（2）信用证内应明确规定卖方有权可多装或少装所注名的百分数，并按实际装运数量议付。（信用证之金额应较本售货合约的金额增加相应的百分数）

　　The Sellers reserve the option of shipping the indicated percentage more or less than the quantity hereby contracted, and the covering Letter of Credit shall be negotiated for the amount coveringthe value of quantity actually shipped. (The Buyers are requested to establish the L/C in accordwith the indicated percentage over the total value of order as per this Sales Contract.)

　　（3）信用证内容须严格符合本售货合约的规定，否则修改信用证的费用由买方负担，卖方亦不负因修改信用证而延误装运的责任。并保留因此而发生的一切损失的索赔权。

　　The contents of the covering Letter of Credit shall be in strict accordance with stipulations of the Sales Contract; in case of any variation thereof necessitating amendment of the L/C, the Buyersshall bear the expenses for effecting the amendment. The sellers shall not be held responsible for possible delay of shipment resulting from awaiting the amendment of the L/C, and reserve the right to claim from the Buyers compensation for the losses resulting therefrom.

　　（4）除经约定保险归买方投保者外，由卖方向中国的保险公司投保。如买方须增加保险额或须加保其他险，可于装船前提出，经买方同意后代为投保，其费用由买方负担。

　　Except in case where the insurance is covered by the Buyers as arranged, insurance is to becovered by the Sellers with a Chinese insurance company. If insurance for additional amountand/or for other insurance terms is required by the Buyers, prior notice to this effect mush reach the Sellers before shipment and is subject to the Sellers’ agreement, and the extra insurance premium shall be for the Buyers’ account.

　　（5）买方须将申请许可证副本（经有关银行副署）寄给卖方俟许可证批出后再即用传真通知卖方，假如许可证被驳退，买方须征得卖方的同意方可重行申请许可证。

　　The Buyers are requested to send to the Sellers authentic copy of the License-application

　　(endorsed by the relative bank) filed by the Buyers and to advise the Sellers by fax immediately

　　when the said License is obtained. Should the Buyers intend to file reapplication for License

　　in cases of rejection of the original application, the Buyers shall contact the Sellers and obtain the

　　latter’s consent before filing reapplication.

　　（6）商品检验：产地证明书或中国有关机构所签发的品质数量/重量检验证，作为品质数量/ 重量的交货依据。

　　INSPECTION : The Certificate of Origin and/or the Inspection Certification of

　　Quality/Quantity/Weight issued by the relative institute shall be taken as the basis for the shipping Quality/Quantity/Weight

　　（7）因人力不可抗拒事故，使卖方不能在本售货合约规定期限内交货或不能交货，卖方不负责任，但是卖方必须立即以传真通知买方，如果买方提出要求，卖方应以挂号函向买方提供由中国国际贸易促进委员会或有关机构出具的证明，证明事故的存在。买方不能领

　　到进口证不能被认为系属人力不可抗拒范围。

　　The Sellers shall not be held responsible if they owing to Force Majeure cause or causes fail to

　　make delivery within the time stipulated in this Sales contract or cannot delivery the goods.

　　However the Sellers shall inform immediately the Buyers by fax. The Sellers shall delivery to

　　the Buyers by registered letter, if it is requested by the Buyers, a certificate issued by the China

　　council for the Promotion of International Trade or by any competent authority, certifying to the

　　existence of the said cause or causes. Buyers’ failure to obtain the relative Import license is notto be treated as Force Majeure.

　　（8）仲裁：凡因执行本合约或有关本合约所发生的一切争执，双方应以友好方式协商解决，如果协商不能解决，应提交北京中国国际贸易促进委员会对外贸易仲裁委员会根据中国国际贸易促进委员会对外贸易仲裁委员会的仲裁程序暂行规则进行仲裁，仲裁裁决是终局的，对双方都有约束力。

　　ARBITRATION : All disputes arising in connection with the Sales Contract of the execution thereof shall be settled amicably by negotiation. In case no settlement can be reached, the case under dispute shall then be submitted for arbitration to the Foreign Trade Arbitration commission of the China Council for the Promotion of International Trade in accordance with the ProvisionalRules of Procedure of the Foreign Trade Arbitration commission of the China council for thePromotion of International Trade. The decision of the Commission shall be accepted as final andbinding upon both parties.

　　买方卖方 THE BUYERSTHE SELLERS

英文合同篇7

　　一.hereby

　　英文释义:by means of , by reason of this

　　中文译词:特此,因此,兹

　　用法:常用于法律文件、合同、协议书等正式文件的开头语；在条款中需要强调时也可用。

　　语法：一般置于主语后,紧邻主语.

　　例1：

　　The Employer hereby covenants to pay the Contractor in consideration of the execution and completion of the Works and the remedying of defects therein the Contract Price or such other sum as may become payable under the provisions of the Contract at the time and in the manner prescribed by the Contract.

　　参考译文:

　　业主特此立约保证在合同规定的期限内,按合同规定的方式向承包人支付合同价,或合同规定的其它应支付的款项,以作为本工程施工、竣工及修补工程中缺陷的报酬。

　　注释:

　　(1)hereby: by reason of this 特此

　　(2)covenant: v. make a formal agreement 立约,签订合同、条约; n. legal agreement具有法律约束的正式合同

　　(3)completion of the Works: 工程的竣工

　　(4)therein: in the Works在本工程中

　　(5)the Contract Price: 合同总价,指工程的总造价

　　(6)such...as: 关系代词,相当于that, which

　　(7)under: in accordance with 根据,按照

　　(8)the provisions of the Contract: terms and conditions of the Contract合同条款

　　例2：

　　We hereby certify to the best of our knowledge that the foregoing statement is true and correct and all available information and data have been supplied herein, and that we agree to provide documentary proof upon your request.

　　注释：

　　（1）hereby：特此

　　（2）to the best of our knowledge：as far as we know据我们所知

　　（3）foregoing statement：above-mentioned statement上述声明

　　（4）herein：in this, in the statement在声明中

　　（5）documentary proof：证明文件

　　参考译文：

　　特此证明，据我们所知，上述声明内容真实，正确无误，并提供了全部现有的.资料和数据，我们同意，应贵方要求出具证明文件。

　　例3：

　　This Contract is hereby made and concluded by and between Co. (hereinafter referred to as Party A) and Co. (hereinafter referred to as Party B) on (Date), in (Place), China, on the principle of equality and mutual benefit and through amicable consultation.

　　注释：

　　（1）hereby：特此

　　（2）hereinafter referred to as Party A：以下称甲方

　　（3）on the principle of equality and mutual benefit：在平等互利基础上

　　（4）through amicable consultation：通过友好协商

　　参考译文：

　　本合同双方，公司（以下称甲方）与公司（以下称乙方），在平等互利基础上，通过友好协商，于年月日在中国（地点），特签订本合同。

　　例4：

　　This agreement is hereby made and entered into on (Date), by and between Co. China (hereinafter referred to as Party A) and Co. (hereinafter referred to as Party B).

　　注释：

　　（1）this agreement is hereby made and entered into：特此订立本协议在法律文件中表示“订立本协议”可用以下4个动词：sign (make, conclude or enter into) this agreement, 按照同义词连用的写作特点，可用上述4个动词中的两个来表示）。

　　（2）hereinafter referred to as Party B：以下简称乙方

　　参考译文：

　　本协议特由中国公司（以下简称甲方）与公司（以下简称乙方）于年月日订立。

　　二 hereof

　　英文释义: of this

　　中文译词:关于此点；在本文件中

　　用法:在表示上文已提及的“本合同的、本文件的??”时，使用该词。例如表示本合同条件、条款时，可以说“the terms, conditions and provisions hereof”，这里hereof表示“of this Contract”；又如表示本工程的任何部分，可用“any parts hereof”，这里hereof表示“of this Works”。语法：一般置于要修饰的名词的后面，与之紧邻。

　　hereof和thereof的区别：hereof强调“of this”。例如，上面的“the terms, conditions and provisions thereof”中的thereof表示of the Contract；“any parts thereof”中的thereof表示of the Works。

　　例1

　　Whether the custom of the Port is contrary to this Clause or not, the owner of the goods shall, without interruption, by day and night, including Sundays and holidays (if required by the carrier), supply and take

　　delivery of the goods. Provided that the owner of the goods shall be liable for all losses or damages including demurrage incurred in default on the provisions hereof.

　　注释：

　　（1） Whether the custom of the Port is contrary to this Clause or not：不论港口习惯是否与本款规定相反，whether? or not：不论??是否

　　（2） the owner of the goods：货方

　　（3） without interruption：无间断地

　　（4） carrier：承运人

　　（5） in default on the provisions hereof：违反本款规定 hereof：of this Clause

　　参考译文：

　　不论港口习惯是否与本款规定相反，货方都应昼夜地，包括星期日和假日（如承运人需要），无间断地提供和提取货物。货方对违反本款规定所引起的所有损失或损坏，包括滞期应负担赔偿责任。

　　例2

　　Foreign trade dealers as mentioned in this Law shall, in accordance with the provisions hereof, cover such legal entities and other organization as are engaged in foreign trade dealings.

　　注释：

　　（1） foreign trade dealers：对外贸易经营者

　　（2） as mentioned in this Law：本法所称

　　（3） the provisions hereof：the provisions of this Law 本法规定

　　（4） legal entity：法人

　　（5） be engaged in foreign trade dealings：从事对外贸易经营活动参考译文：

　　本法所称对外贸易经营者，是指依照本法规定从事对外贸易经营活动的法人和其他组织。

　　例3

　　The establishment of a limited liability company or a company limited by shares shall comply with the conditions and provisions of this Law. A company complying with the conditions and provisions hereof may be registered as a limited liability company or a company limited by shares. Provided that if a company fails to comply with the conditions and provisions hereof, the company in question shall not be registered as a limited liability company or a company limited by shares.

　　注释：

　　（1）a limited liability company：有限责任公司

　　（2）a company limited by shares：股份有限公司

　　（3）provisions hereof：本法规定 hereof: of this Law

　　（4）may be registered as：登记为

　　参考译文：

　　设立有限责任公司、股份有限公司，必须符合本法规定的条件。符合本法规定的条件的，登记为有限责任公司或者股份有限公司；不符合本法规定的条件的，不

　　得登记为有限责任公司或股份有限公司。

　　例4

　　If, as a result of withdrawal or any other reasons, an arbitrator fails to perform his duties as an arbitrator, another arbitrator shall, in accordance with the provisions hereof, be selected or appointed. 注释：

　　（1） as a result of withdrawal or any other reasons：回避或者其它原因

　　（2） arbitrator：仲裁员

　　（3） the provisions hereof：the provisions of this Law 本法规定

　　（4） be selected or appointed：选定或指定

　　参考译文：

　　仲裁员因回避或者其它(转载于:wWw.cnboThwiN.cOM 博威范文网:协议书英文怎么写)原因不能履行职责的，应当依照本法规定重新选定或指定仲裁员。

　　例5

　　In the event of conflict between the provisions on arbitration formulated and prepared prior to the effective date of this Law and the provisions of this Law, the provisions hereof shall prevail.

　　注释：

　　（1） conflict：相抵触

　　（2） prior to the effective date of this Law：本法施行前

　　（3） the provisions hereof shall prevail：以本法为准 hereof：of this Law 参考译文：

　　本法施行前制定的有关仲裁的规定与本法的规定相抵触的，以本法为准。例6

　　Where, in accordance with laws, the circumstance(s) specified in Article 15 and Article 16 of this Law is /are confirmed, the organization with compensatory obligations shall pay compensation in any of the circumstance in question.

　　Where the claimant for compensation demands the confirmation of one of the circumstances specified in Article 15 and Article 16 hereof, and the demanded organization refuses to make the confirmation, the claimant shall have the right to lodge a complaint. Where the claimant claims compensation, the claim, shall, first, be lodged to the organization for compensatory obligations.

　　The provisions of Article 10, Article 11 and Article 12 hereof shall apply to/ in the procedures of compensation.

　　注释：

　　（1） the organization with compensatory obligations：赔偿义务机关

　　（2） shall pay compensation：应当给予赔偿

　　（3） the claimant for compensation：赔偿请求人

　　（4） Article 15 and Article 16 hereof：本法第十五条、第十六条 hereof：of this Law

　　（5） shall have the right to lodge a complaint：有权申诉

　　（6） claims compensation：要求赔偿

　　（7） apply to/ in：适用 More Examples: The comment applies equally here. /That argument does not apply in this case. /That applies to at least nine-tenths of the people we see about. /These remarks apply to every town in this kingdom. /The rules of safe driving apply to everyone. 参考译文：

　　赔偿义务机关对依法确认有本法第十五条、第十六条规定的情形之一的，应当给予赔偿。

　　赔偿请求人要求确认有本法第十五条、第十六条规定情形之一的，被要求的机关不予确认的，赔偿请求人有权申诉。赔偿请求人要求赔偿，应当先向赔偿义务机关提出。赔偿程序适用本法第十条、第十一条、第十二条的规定。

　　例7

　　If an arbitrator involved in one of circumstances specified in Item 4, Article 34 of this Law, and if it is serious, or those specified in Item 6, Article 58 hereof, the arbitrator in question shall, in accordance with the law, bear the legal liability and responsibility. The arbitration commission shall remove the name of the arbitrator in question from the list of arbitrators.

　　注释：

　　（1） arbitrator：仲裁员

　　（2） Article 58 hereof：本法第五十八条 hereof：of this Law

　　（3） bear the legal liability and responsibility：承担法律责任

　　（4） the arbitration commission：仲裁委员会

　　（5） remove the name of the arbitrator in question from the list of arbitrators：将其除名

　　参考译文：

　　仲裁员有本法第三十四条第四项规定的情形，情节严重的，或者有本法第五十八条第六项规定的情形的，应当依法承担法律责任，仲裁委员会应当将其除名。例8

　　If, pursuant to this Law, the relevant responsible authorities with the duty of approvals fail to grant approval to such an application as meets the requirements and provisions hereof, or the company registration authorities fail to register a company whose application meets the requirements hereof, the party in question may, in accordance with laws, apply for reconsideration or bring an administrative suit.

　　注释：

　　（1） the relevant responsible authorities with the duty of approvals：履行审批职责的有关主管部门

　　（2） meets the requirements and provisions hereof：符合本法条件

　　（3） the company registration authorities：负责公司登记的主管部门

　　（4） the requirements hereof：本法条件 hereof: of this Law

　　（5） apply for reconsideration：申请复议

　　（6） bring an administrative suit：提起行政诉讼

英文合同篇8

　　1. 兹经买卖双方同意按照以下条款由买方购进，卖方售出以下商品： This contract is made by and between the Buyers and the Sellers, whereby the Buyers agree to buy and the Sellers agree to sell the goods referenced hereunder subject to the terms and conditions as stipulated hereinafter:

　　2. 索赔:在货到目地口岸45天内如发现货物品质、规格和数量与合同不符，除属保险公司或船方责任外，买方有权凭中国商检出具的检验证书或有关文件向卖方索赔。

　　Claims: within 45 days after the arrival of the goods at the destination, should the quality, specifications or quantity be found not in conformity with the stipulations of the contract except those claims for which the insurance company or the owners of the vessel are liable, the Buyers shall, have the right on the strength of the inspection certificate issued by the C.C.I.C and the relative documents to claim compensation from the Sellers.

　　3. 不可抗力：由于不可抗力的缘由发生在制造、装载或运输的过程中导致卖方延期交货或不能交货者，卖方可免除责任；在不可抗力发生后，卖方须立即电告买方及在14天内以空邮方式向买方提供事故发生的证明文件；在上述情况下，卖方仍须负责采取措施尽快发货。

　　Force Majeure: The Sellers shall not held responsible for any delay in shipment or non-delivery of the goods due to Force Majeure, which might occur during the process of manufacturing or in the course of loading or transit. The sellers shall advise the Buyers forthwith of the occurrence mentioned above within fourteen days thereafter. The Sellers shall send by airmail to the Buyers for their acceptance certificate of the accident. Under such circumstances the Sellers, however, are still under the obligation to take all necessary measures to hasten the delivery of the goods.

　　4. 不可抗力：本合同内所述全部或部分货物，如因不可抗力原因，以致不能履约或不得不延期交货，卖方概不负责。

　　Force Majeure: The Seller shall not be held liable for failure delay delivery of the entire lot or a portion of the commodity under this Contract in consequence of and force majeure.

　　5. 仲裁：凡有关执行合同所发生的一切争议应通过友好协商解决，如协商不能解决，则将分歧提交中国国际贸易促进委员会按有关仲裁程序进行仲裁，仲裁将是终局的，双方均受其约束，仲裁费用由败诉方承担。

　　Arbitration: All disputes in connection with the execution

　　of this Contract shall be settled through friendly negotiations. In case no settlement can be reached, the case may then be submitted for arbitration to the Arbitration Commission of the China Council for the Promotion of International Trade in accordance with the Provisional Rules of Promulgated by the said Arbitration Commission. The Arbitration Committee shall be final and binding upon both parties, and the arbitration fee shall be borne by the losing party.

　　6. 仲裁：在履行本合同中所发生的或者与合同有关的一切争执，由双方协商解决。如果协商后仍不能解决时，得提请仲裁。仲裁在中国进行，由中国国际经济贸易仲裁委员会根据该仲裁委员会的仲裁程序规则进行仲裁。仲裁裁决为最终决定，对买卖双方都有约束力。除该仲裁委员会另有决定外，仲裁费用由败诉一方负担。 Arbitration: Any and all disputes arising from or in connection with the performance of the Contract shall be settled through negotiation by both parties, failing which they shall be submitted for arbitration. The arbitration shall take place in China and shall be conducted by China International Economic and Trade Arbitration Commission in accordance with the rules of procedures of the said commission. The arbitration award shall be final and binding

　　upon both Buyer and Seller. Unless otherwise awarded by the said arbitration commission, the arbitration fees shall be borne by the losing party.

　　7. 卖方交货的义务以在上述交货日期前收到买方按第九条的规定开出的信用证或预付款为条件。如按合同条款运输工具由买方选订，卖方将在上述日期将货物备好。

　　However, the seller’s obligation to deliver is conditional upon receipt from the Buyer of a letter of credit or advance payment in accordance with Clause 9 of this Contract days before the time of delivery stipulated hereof. If a carrier is selected and booked by the Buyer itself in accordance with the terms of this Contract, the Seller will have the commodity ready for shipment by such time of delivery.

　　8. 付款条件：凭以卖方为受益人的、100%保兑的、不可撤销的、无追索权的.、可以转运的及分批发运的即期信用证，议付期至装运日期后第15天在中国到期。买方在信用证上请填注本合同号码，货物名称要按本合同规定确定。

　　Payment: By 100% confirmed, irrevocable, without recourse L/C, in favor of the Seller, available by sight draft, allowing transshipment and partial shipments, valid for negotiation in China until the 15th day after the date of shipment. The Buyer is requested always to quote in the L/C

　　the number of this Contract and the names of the commodity in accordance herewith.

　　9. 保险：按照中国人民保险公司的保险条款，按发票金额的110%投保但不包括罢工、x乱和民变险，保至目的口岸为止。如买方要增加保额或保险范围，应于装运前经卖方同意，因此而增加的保险费由买方负责。

　　Insurance: For 110% of invoice value, up to the port of destination, as per the insurance clauses of the People’s Insurance Company of China, excluding SRCC Risks. If additional insurance amount or coverage in required, the Buyershall have the consent of the Seller before shipment, and the additional premium thus incurred shall be borne by the Buyer.

　　10.包装：所有在本合同项下出售的货物将以卖方认为适合于第五条规定的运输方式的包装材料包装。如果对包装有其他要求，买方应征得卖方同意并承担由此而增加的一切额外费用。

　　Packing: All the commodities sold thereunder will be packed with packing materials deemed by the Seller suitable for the mode of transportation stipulated in Clause 5 hereof. If additional requirement for packing is needed, the Buyer shall have the consent of the Seller and bear all the extra charges thus incurred.

【英文合同】相关文章：

英文合同范本07-05